Effective Date: 01-01-2026

Welcome to the Arohan Interiors website. By accessing or using this website, you agree to comply with and be bound by the following Terms & Conditions. If you do not agree, please do not use this website.

1. About Us

Arohan Interiors is an interior design studio offering residential and commercial interior design services. Information on this website is provided for general reference and enquiry purposes only.

2. Use of Website

  • The content on this website is for informational purposes only.
  • You may not copy, reproduce, or distribute any content, images, or designs without prior written permission.
  • Misuse of the website, including attempting to disrupt its functionality, is strictly prohibited.

3. Intellectual Property

All content on this website, including text, images, designs, logos, and graphics, is the intellectual property of Arohan Interiors unless stated otherwise. Unauthorized use may result in legal action.

4. Project Enquiries & Estimates

  • Submitting an enquiry does not constitute a confirmed engagement.
  • All quotations, estimates, and timelines provided are indicative and subject to change based on project scope, site conditions, material availability, and client approvals.
  • Final project terms will be governed by a separate written agreement or work order.

5. Payments

  • Payment terms will be clearly outlined in the proposal or invoice shared with the client.
  • Project commencement is subject to receipt of the agreed advance payment.
  • Delays in payment may result in project delays or suspension of services.

6. Design & Execution

  • Design concepts, drawings, and visual representations are indicative in nature.
  • Minor variations may occur during execution due to material availability, site constraints, or technical considerations.
  • Arohan Interiors will not be responsible for delays caused by third-party vendors, contractors, or unforeseen circumstances beyond our control.

7. Limitation of Liability

Arohan Interiors shall not be liable for:

  • Any indirect, incidental, or consequential damages
  • Losses arising from misuse of information on this website
  • Delays caused due to force majeure events, vendor delays, or client-side dependencies

8. Third-Party Links

This website may contain links to third-party websites for reference. Arohan Interiors has no control over their content or practices and is not responsible for any issues arising from their use.

9. Termination

We reserve the right to suspend or terminate access to our website or services if these Terms & Conditions are violated.

10. Governing Law

These Terms & Conditions shall be governed and interpreted in accordance with the laws of India. Any disputes shall be subject to the jurisdiction of the courts of [City/State].

11. Updates to Terms

Arohan Interiors reserves the right to modify these Terms & Conditions at any time. Updated terms will be posted on this page with a revised effective date.

12. Contact Information

For any questions regarding these Terms & Conditions, please contact:

Arohan Interiors